All cases
International Arbitration
Contractor claim on a metro line
Lead counsel for the contractor in an ICC arbitration over delay and disruption on an urban rail project.
Client
International contractor
Sector
Construction
Jurisdiction
ICC, Paris seat
Year
2024
Value
EUR 145m
Outcome
Award for the client
The matter
Design changes and late access to sites pushed the project two years past completion. The employer withheld payment and called the performance bond.
What we did
We built the delay case with two expert teams and obtained interim relief against the bond call.
Result
The tribunal awarded the client most of its claim plus interest and costs.
